April 22, 2023 Issue, Page 7 of 14

Page Text

Classifieds April 22, 2023 The Elk City News - 7 lost revenue, the difference between the Bidder’s proposed Contract Sum and (580)-225-2010 Telephone 915 W.B. Ave Gene Cobb Auction & Realty the Contract Sum as awarded and costs to re bid the Project should such action (580)-225-2011 Fax Elk City, OK 73644 become necessary. Such bid securities will be returned to the unsuccessful bid- markomarkalbertlaw.com Jamie Potter as Personal Representa- ders after execution of the Contract. For information concerning any part of the tive proposed work, contact the Architect: Prairie Rock Architecture PLLC (PRA), RO. of the Estate of Robert Henry Potter Richard E, “Gene” Cobb Box 2618, Blanchard, OK 73010. Telephone (405) 2558202. Additional bidding instructions are included in the Bidding Requirements bound into the Contract 915 W.B. Ave Elk City, OK 73644 Documents. Dustin Deal, LLC 580-225-6743 ‘The Owner reserves the right to reject any or all bids and waive formalities and irregularities CERTIFICATE OF MAILING 11182 N. 2030 Rd. Elk City, OK 73644 BY: Sweetwater Public Schools 11107 North Highway 30, Sweetwater, Oklahoma I, Mark W. Albert, hereby certify that LP Venture Capital, Inc. Auctioneer * Real Estate Broker 73666 Tmailed a true and correct copy of the P.O. Box 1598 above and foregoing Elk City, OK 73648 Certified Appraiser Publish two times (April 15 & 2023) in the Elk CityNews: Publish one time (April 2,2 in the Elk City News. ‘Amended Notice of Hearing Motion to Confirm Sale to the following: ‘on this the 19th day of April, 2023, with proper postage thereon fully IN THE DISTRICT COURT OF IN THE DISTRICT COURT OF ‘Tammy Cape prepaid DO OOOO BECKHAM COUNTY BECKHAM COUNTY 518 N, Jefferson STATE OF OKLAHOMA Elk City, OK 73644 STATE OF OKLAHOMA Mark W. Albert IN THE MATTER OF THE ESTATE Jamie Potter Constructio PUBLISHER'S NOTICE GREAT PLAINS NATIONAL BANK, All real estate advertised herein CAROL JO BARTLETT, ‘a Corporation, McLemore Sand & Topsoil. is subject to the Federal Fair Deceased. Plaintiff, Loading and Hauling, i. 2 Sn aberica’ "any prsernea Housing Act, which makes it illegal Case No. PB-2022-75 Washed Masonry Sand. Sand limitation, or discrimination vs. Loam. Red Bed. Fill Sand. because of race, color, religion, NOTICE OF HEARING PETITION 243-7496 or sex, handicap, familial ‘status or FOR DECREE OF DISTRIBUTION, ‘TAMMY CAPE, JAMIE POTTER, national origin, or intention to make ‘APPROVAL OF 243-3426 (Fax) any such preference, limitation or ATTORNEYS’, FEES, COSTS, AND JAMIE POTTER AS PERSONAL discrimination.” EXPENSES, AND DISCHARGE OF REPRESENTATIVE OF THE This newspaper will not knowingly PERSONAL ESTATE OF ROBERT HENRY POT- For Rent accept any advertising for real estate which is in violation of REPRESENTATIVE TER, the law. All persons are hereby Defendants. Nice Clean 2bd House 107 Thor- informed that all dwellings Notice is hereby given to all persons advertised are available on an equal interested in the Estate of CAROL JO Case No. CJ-2022-149 ton Elk City, OK $700.00 per ‘opportunity basis, BARTLETT, Deceased, that on the 28th day of October, 2022, the Will AMENDED NOTICE OF HEARING PICKUP ov DELIVERY month $700.00 Deposit. Call 580- 323-4242 or 580-331-9843 of CAROL JO BARTLETT, dated July MOTION TO CONFIRM SHERIFF'S 18, 2022, was admitted to probate, SALE Letters Testamentary issued to STONE RAY BATEY, as Personal ‘TO: Tammy Cape, Jamie Potter, Jamie Representative of the Estate to serve Potter as Personal Representative of without bond, a judicial determi- the Estate of Robert Henry $50 $75 nation of the heirs, devisees and Potter, Dustin Deal, LLC, and LP Publish two times (April 15 & 22,2023) in the Elk City News. legates of the Decedent, all of Venture Capital, Inc. which was granted. ‘Take notice that the Plaintiff, Great INVITATION TO BID Plains National Bank has filed herein Pursuant to an Order of this Court its Amended Motion to Sealed bids addressed to the Owner will be received at the Place of Bid until the made on 11 th day ofApril, 2023, Confirm Sheriff's Sale in the above en- Time of Bid on the Bid Date and then will be opened and read publicly the same notice is given that the 15 th day of titled cause concerning the following date and hour. May, 2023, at 11:00 am, is the day described real property situated in and time that the PETITION FOR DE- Beckham County, State of Oklahoma, PROJECT: 2023 Classroom Addition CREE OF DISTRIBUTION, APPROV- to-wit: 6 Months 1 Yea OWNER: Sweetwater Public Schools AL OF ATTORNEYS’, FEES, COSTS, Board of Education AND EXPENSES, AND DISCHARGE 7.1428 mineral acre interest lying in 11107 North Highway 30 OF PERSONAL REPRESENTATIVE Section 7, Township 11 North, Range Add the e-paper to a print subsorjation for $1 er month Sweetwater, OK 73666 will be heard in the Second Floor 21 W.LM., Beckham Courtroom of the Beckham County County, Oklahoma. BID DATE: Thursday May 12 th, 2023 (05-12-2023) Courthouse, Sayre, Oklahoma, and all TIME OF BID: 2:00 PM CDT. persons interested may appear and ‘That said Amended Motion to PLACE OF BID: Board Room, 11107 North Highway 30, Sweetwater, Oklahoma contest the same Confirm Sale will be heard before the 73666 Honorable Jill Weedon at the /S/ Michelle K. Roper Beckham County Courthouse on the Any bids received after the stated Time of Bid will be returned to the Bidder un- apened. Bidding Requirements and Documents, including Drawings, Specifica- tions and Addenda may be obtained at the office of Prairie Rock Architecture, PLLC, or by mail, A deposit sum of $150.00, JUDGE OF THE DISTRICT COURT 10th day of May, 2023, at 9:30 o'clock Timothy P. Israel, Attorney at Law, OBA No. 4564 a.m. You must appear at said time and present any objection to said sale proceeding or the Amended Motion to “ElkCityNews hich may be in the form of a check written on the bidder's business account 119 S Jefferson, AVE Confirm Sale will be sustained and the sale confirmed. made payable to the Architect, will be required for each set of Contract Docu- ‘ments. Digital versions of Documents are available on CD for a nonrefundable PO Box 1596 Elk City, OK 73648 109 W. Broadway Mark W. Albert, OBA #12575 deposit of $25.00. Deposits will be refunded to Bidders who submit a bona fide Bid at the time and place designated herein and who return the Bidding Docu: Phone: 580-225-1411 timothy.p.israelegmail.com PO Box 1748 580-225-3000 + www.elkcityoknews.com ments to the Architect in good condition within ten (10) days from the bid date. Elk City, OK 73648 Ihe full and complete replacement cost of missing, damaged or unreturned Bid- ding Documents will be deducted from the Bidders deposit. The full replacement zost for complete sets of Bidding Documents will be deducted from the mail your legals to deposits of Bidders who do not submit a bona fide Bid and do not return the Bid- ding Documents to the office of the Architect in good condition within five (5) Jays from the date they received them or no later than seven (7) days grior to bid date. Bidding Documents shall be returned to the Architect's Of- fice postage paid. The Architect will not accept delivery of Bidding Documents returned C.O.D,, freight collect or other similar methods. All Bidding Requirements and Documents remain property of the Architect. The Bidding Documents are on file at the Architect's office and are available and open for inspection by Bidders and Sub bidders by appointment during normal [email protected] ousiness hours. In submittinga bid it is agreed that the Bid may not be with- drawn fora period of thirty (30) days after Bid Date. A Bid Security in the form of a cashier's check, or certified check, or acceptable bidder's surety bond, made gayable to the Owner, in an amount that is not less than five percent (5%) of the Bid proposal submitted, including all Alternates, shall accompany each Bid as a juarantee that: (1) the Bid er will not modify, withdraw or cancel the droposal for thirty (30) days after the bid date; and (2) the bidder, if awarded the Published on Wednesdays and Saturdays zontract, will promptly enter into a contract and execute such bonds and furnish such insurance certificates as may be required. Should the Bidder fail to honor these two (2) guarantee for any reason, the Owner shall total his damages and shall deduct the amount of such damages from the Bidder's Bid Security. Should hhe damages total less than the amount of the Bid Security, the difference shall be returned to the Bidder. However, all damages in excess of the Bid Security shall be borne by the Owner. Damages may include, out shall not be limited to, reasonable compensation for theOwner’s additional time spent, additional Architect's fees, costs to the Owner for delays in comple- ion of the Work based upon the Bidders proposed Contract Time and the Contract Time as Awarded including, but not limited to, interest expense and Looking fot a eat ft for your company? Put your help wanted in the classifieds to reach more local candidates. Send your Help Wanted to [email protected]